Purchase Order Terms And Conditions

1. Applicability (Entire Agreement):

1.1      These terms and conditions of sale (these “Terms”) are the only terms which govern the sale of the goods identified on Buyer’s purchase order (the “Goods”) by Seller to Buyer. By placing a purchase order and executing on a Sellers Quote, Buyer makes an offer to purchase the Goods pursuant to these Terms, including (a) a list of the Goods to be purchased; (b) the quantity of each of the Goods ordered; (c) the requested delivery date; (d) the unit Price for each of the Goods to be purchased; (e) the billing address; and (f) the delivery location (the “Basic Purchase Order Terms”), and on no other terms.

1.2     The accompanying quotation, proposal, confirmation of sale, invoice, order acknowledgment or similar document delivered by Seller to Buyer (the “Sales Confirmation”), the Basic Purchase Order Terms and these Terms (collectively, this “Agreement”) comprise the entire agreement between the parties, and supersede all prior or contemporaneous understandings, agreements, negotiations, representations and warranties, and communications, both written and oral. These Terms prevail over any of Buyer’s general terms and conditions of purchase regardless of whether or when Buyer has submitted its purchase order or such terms. Fulfillment of Buyer’s order does not constitute acceptance of any of Buyer’s terms and conditions and does not serve to modify or amend these Terms.

1.3     Notwithstanding anything herein to the contrary, if a written contract signed by both parties is in existence covering the sale of the Goods covered hereby, the terms and conditions of said contract shall prevail to the extent they are inconsistent with these Terms.

2. Non-delivery:

2.1     The quantity of any installment of Goods as recorded by Seller on dispatch from Seller’s Shipment Point (as defined in Section 4) is conclusive evidence of the quantity received by Buyer on delivery unless Buyer can provide conclusive evidence proving the contrary.

2.2     Seller shall not be liable for any non-delivery of Goods (even if caused by Seller’s negligence) unless Buyer gives written notice to Seller of the non-delivery within 10 days of the date when the Goods would in the ordinary course of events have been received.

2.3     Any liability of Seller for non-delivery of the Goods shall be limited to replacing the Goods within a reasonable time or adjusting the invoice respecting such Goods to reflect the actual quantity delivered.

3. Delivery:

3.1     The Goods will be delivered within a reasonable time after the receipt of Buyer’s purchase order, subject to availability of finished Goods. The delivery and/or shipping schedule is the best estimate possible based on conditions existing at the time of Seller’s Sales Confirmation or Seller’s quotation and receipt of all specifications, as applicable, and in the case of non-standard items, any such date is subject to Seller’s receipt of complete information necessary for design
and manufacture. Seller shall not be liable for any delays, loss or damage in transit or for any other direct, indirect, or consequential damages due to delays,
including without limitation, loss of use.

3.2     Seller may, in its sole discretion, without liability or penalty, deliver partial shipments of Goods to Buyer and ship the Goods as they become available, in
advance of the quoted delivery date. If the Goods are delivered in installments, then insofar as each shipment is subject to the same Agreement, the
Agreement will be treated as a single contract and not severable.

3.3     Seller shall make the Goods available to Buyer at Seller’s factory or designated shipment point (each, “Seller’s Shipment Point”) using Seller’s standard methods for packaging and shipping such Goods. Buyer shall take delivery of the Goods within 5 days of Seller’s written notice that the Goods have been delivered to the Seller’s Shipment Point.

3.4     If for any reason Buyer fails to accept delivery of any of the Goods on the date fixed pursuant to Seller’s notice that the Goods have been delivered at the
Seller’s Shipment Point, or if Seller is unable to deliver the Goods at the Seller’s Shipment Point on such date because Buyer has not provided appropriate instructions, documents, licenses or authorizations: (i) title and risk of loss to the Goods shall pass to Buyer; (ii) the Goods shall be deemed to have been delivered; and (iii) Seller, at its option, may store the Goods until Buyer picks them up, whereupon Buyer shall be liable for all related costs and expenses (including, without limitation, storage and insurance).

4. Shipping Terms:

Unless otherwise mutually agreed to in writing by the parties, delivery shall be FCA (Seller’s Shipment Point) or EXW, at Seller’s sole discretion. At Buyer’s request, Seller will, at Buyer's risk and expense, arrange for the delivery of the Goods to Buyer's site/facility and Buyer will pay, or reimburse Seller, for all freight charges, taxes, duties, entry fees, brokers’ fees, special, miscellaneous and all other ancillary charges and special packaging charges incurred.

5. Title Transfer and Risk of Loss:

Title passes to Buyer upon the earlier of (i) delivery of the Goods at the Seller’s Shipment Point or (ii) deemed delivery pursuant to clause 3.4 above. As collateral security for the payment of the purchase price of the Goods, Buyer hereby grants to Seller a lien on and security interest in and to all of the right, title and interest of Buyer in, to and under the Goods, wherever located, and whether now existing or hereafter arising or acquired from time to time, and in all accessions thereto and replacements or modifications thereof, as well as all proceeds (including insurance proceeds) of the foregoing. The security interest granted under this provision constitutes a purchase money security interest. Risk of Loss passes to Buyer upon the earlier of (i) delivery of the Goods at the Seller’s Shipment Point or (ii) deemed delivery pursuant to clause 3.4 above unless the Goods are insured in shipment by Seller and stated in writing on the accompanying quotation, proposal, or sales confirmation.

6. Inspection Nonconforming Goods:

6.1     Buyer shall inspect the Goods within 10 days of receipt (the “Inspection Period”). Buyer will be deemed to have accepted the Goods unless it notifies Seller in writing of any nonconforming Goods during the Inspection Period and furnishes such written evidence or other documentation as required by Seller. Such notification shall identify each and every alleged nonconformity of the Goods and describe that portion of the shipment being rejected. Seller shall then respond with instructions as to the disposition of the Goods.

6.2     If Buyer timely notifies Seller of any nonconforming Goods, Seller shall, in its sole discretion, (i) replace such nonconforming Goods with conforming Goods, or (ii) credit or refund the Price for such nonconforming Goods, together with any reasonable shipping and handling expenses incurred by Buyer in connection therewith. Buyer shall ship, at its expense and risk of loss, the nonconforming Goods to Seller’s Shipment Point. If Seller exercises its option to replace nonconforming Goods, Seller shall, after receiving Buyer’s shipment of nonconforming Goods, ship to Buyer, at Buyer’s expense and risk of loss, the replaced Goods to the Seller’s Shipment Point.

6.3     Buyer acknowledges and agrees that the remedies set forth in Section 6.2 are Buyer’s exclusive remedies for the delivery of Nonconforming Goods. Except as provided under Section 6.2, all sales of Goods to Buyer are made on a one-way basis and Buyer has no right to return Goods purchased under this Agreement to Seller.

7. Services:

Seller will provide such services as are expressly described in the Sales Confirmation (collectively, the “Services”), during normal business hours, unless otherwise specified in the Sales Confirmation. Services requested or required by Buyer outside of these hours or in addition to the quoted or agreed upon services will be charged at Seller’s then current schedule of rates, including overtime charges, if applicable, and will be in addition to the charges outlined in the Sales Confirmation.

8. Purchase Price:

The price for the Goods and/or Services thereof shall be Seller’s quoted price. The Purchase Price is based on the items on the valid Quote, Price List, Sales Confirmation or applicable contract documents. Notwithstanding anything to the contrary set out herein, in the event of any delay to Seller’s delivery schedule caused by Buyer or its representatives (other than for Force Majeure or delays caused by Seller), including without limitation, a suspension of work or the project, a postponement of the delivery date or failure to timely issue of a notice of commencement or similar document, then the Purchase Price shall increase by 1% for every month or partial month of such delay and this Agreement shall be construed as if the increased Purchase Price were originally inserted herein, and Buyer shall be billed by Seller on the basis of such increased Purchase Price.

9. Taxes:

The price for the Goods and/or Services thereof shall be Seller’s quoted price. The Purchase Price is based on the items on the valid Quote, Price List, Sales Confirmation or applicable contract documents. Notwithstanding anything to the contrary set out herein, in the event of any delay to Seller’s delivery schedule caused by Buyer or its representatives (other than for Force Majeure or delays caused by Seller), including without limitation, a suspension of work or the project, a postponement of the delivery date or failure to timely issue of a notice of commencement or similar document, then the Purchase Price shall increase by 1% for every month or partial month of such delay and this Agreement shall be construed as if the increased Purchase Price were originally inserted herein, and Buyer shall be billed by Seller on the basis of such increased Purchase Price.

10. Payment:

10.1     Buyer shall pay all invoiced amounts due to Seller within 30 days from the date of Seller’s invoice. Buyer shall make all payments hereunder by EFT, wire transfer, or check and in the currency invoiced. Payment for foreign billing shall be in accordance with Seller’s written instructions.

10.2     Buyer shall pay interest on all late payments at the rate of 10% per month or the highest rate permissible under applicable law, whichever is greater, calculated daily and compounded monthly. Buyer shall reimburse Seller for all costs incurred in collecting any late payments, including, without limitation, reasonable attorneys’ fees. In addition to all other remedies available under these Terms or at law (which Seller does not waive by the exercise of any rights hereunder), Seller shall be entitled to suspend performance of any Purchase Order, or suspend the delivery of any Goods, if Buyer fails to pay any amounts when due hereunder and such failure continues for 5 days following written notice thereof. Additionally, Seller my require payment in cash, security or other adequate assurance satisfactory to Seller when, in Seller’s opinion, the financial condition of Buyer or other grounds for insecurity warrant such action.

10.3     All sales are subject to the approval of Seller’s credit department.

10.4     Buyer may not withhold or setoff any amounts that may be claimed by Buyer against any amounts that are due and payable to Seller by reason of any set-off of any claim or dispute with Seller, whether relating to Seller’s breach, bankruptcy or otherwise.

11. Limited Warranty:

11.1    Limited Warranty for New Hardware Goods. Seller warrants to Buyer that for a period of twelve (12) months from the date of title transfer of the Goods, including deemed delivery pursuant to clause 3.4 above (the “Warranty Period”), that the Goods manufactured by Seller, when properly installed, maintained, and operated at ratings, specifications and design conditions specified by Seller, will materially conform to Seller’s specifications for such Goods set forth in Seller’s proposal, or, in the absence of such a proposal, such specifications for such Goods appearing in Seller’s product websites, documents, pricelists, quotes, literature or in the Sales Confirmation, at the time of the order and will be free from material defects in material and workmanship (this “Limited Warranty”). Buyer shall notify Seller promptly in writing of any claims within the Warranty Period and provide Seller with an opportunity to inspect and test the Goods or service claimed to fail to meet this Limited Warranty. All claims must be accompanied by full particulars, including system operating conditions, if applicable. If the defects are of such type and nature as to be covered by this Limited Warranty, Seller shall, at its option and in its sole discretion, either: (a) accept return of the defective Goods and furnish replacement Goods; (b) furnish replacement parts for the defective Goods; (c) repair the defective Goods; or (d) accept return of the defective Goods and return payments made, or issue credits for, such defective Goods. If Seller determines that any warranty claim is not, in fact, covered by this Limited Warranty, Buyer shall pay Seller its then customary charges for any additionally required service or products.

11.2     Limited Warranty for New Consumables Goods. Unless otherwise specified, seller warrants to Buyer that for a period of six (6) months from the date of title transfer of the Goods, including deemed delivery pursuant to clause 3.4 above (the “Warranty Period”), that the Goods manufactured by Seller, when properly installed, maintained, and operated at ratings, specifications and design conditions specified by Seller, will materially conform to Seller’s specifications for such Goods set forth in Seller’s proposal, or, in the absence of such a proposal, such specifications for such Goods appearing in Seller’s product websites, documents, pricelists, quotes, literature or in the Sales Confirmation, at the time of the order and will be free from material defects in material and workmanship (this “Limited Warranty”). Buyer shall notify Seller promptly in writing of any claims within the Warranty Period and provide Seller with an opportunity to inspect and test the Goods or service claimed to fail to meet this Limited Warranty. All claims must be accompanied by full particulars, including system operating conditions, if applicable. If the defects are of such type and nature as to be covered by this Limited Warranty, Seller shall, at its option and in its sole discretion, either: (a) accept return of the defective Goods and furnish replacement Goods; (b) furnish replacement parts for the defective Goods; (c) repair the defective Goods; or (d) accept return of the defective Goods and return payments made, or issue credits for, such defective Goods. If Seller determines that any warranty claim is not, in fact, covered by this Limited Warranty, Buyer shall pay Seller its then customary charges for any additionally required service or products.

11.3     No Warranty as to Third Party Products. Products manufactured by a third party (“Third Party Product”) may constitute, contain, be contained in, incorporated into, attached to or packaged together with, the Goods. Third Party Products are not covered by the warranty in Section 11.1. For the avoidance of doubt, seller makes no representations or warranties with respect to any third party product, including any (a) warranty of merchantability; (b) warranty of fitness for a particular purpose; (c) warranty of title; or (d) warranty against infringement of intellectual property rights of a third party; whether express or implied by law, course of dealing, course of performance, usage of trade or otherwise. With respect to any Third Party Product, the warranty, if any, is provided solely through the manufacturer of such Third Party Product, the terms of which vary from manufacturer to manufacturer and Seller assumes no responsibility on their behalf. For Third Party Products, specific warranty terms may be obtained from the manufacturer’s warranty statement.

11.4     No Warranty as to Third Party Software. Software installed by the Buyer on any computer system related to the Goods that interferes with any of the Goods manufactured or supplied by the Seller is not covered under this Warranty. Any resulting damage or functional interference to the Goods of Software installed by the Buyer is also not covered under this Warranty. Software includes but is not limited to networking or security services and any program that is not manufactured, supplied, or installed by the Seller.

11.5     Warranty for Upgrades and Repairs. For Goods that are upgraded with new features and functionality or Goods that are repaired by the Seller, Seller warrants to Buyer for a period of the three (3) months from the date of upgrade or repair that the Goods manufactured by Seller, when properly installed, maintained, and operated at ratings, specifications and design conditions specified by Seller, will materially conform to Seller’s specifications for such Goods set forth in Seller’s proposal, or, in the absence of such a proposal, such specifications for such Goods appearing in Seller’s product websites, documents, pricelists, quotes, literature or in the Sales Confirmation, at the time of the order and will be free from material defects in material and workmanship (this “Limited Warranty”). Buyer shall notify Seller promptly in writing of any claims within the Warranty Period and provide Seller with an opportunity to inspect and test the Goods or service claimed to fail to meet this Limited Warranty. All claims must be accompanied by full particulars, including system operating conditions, if applicable. If the defects are of such type and nature as to be covered by this Limited Warranty, Seller shall, at its option and in its sole discretion, either: (a) accept return of the defective Goods and furnish replacement Goods; (b) furnish replacement parts for the defective Goods; (c) repair the defective Goods; or (d) accept return of the defective Goods and return payments made, or issue credits for, such defective Goods. If Seller determines that any warranty claim is not, in fact, covered by this Limited Warranty, Buyer shall pay Seller its then customary charges for any additionally required service or products.

11.6     Other Limits. Other Limits. Except for the warranties set forth in section 11.1, seller makes no warranty whatsoever with respect to the goods and services, including without limitation any (a) warranty of merchantability; (b) warranty of fitness for a particular purpose; (c) warranty of title; or (d) warranty against infringement of intellectual property rights of a third party; whether express or implied by law, course of dealing, course of performance, usage of trade or otherwise. Seller does not warrant against, and in no event shall Seller be liable for, damages or defects arising out of improper or abnormal use, misuse, abuse, improper installation (other than by Seller), application, operation, maintenance or repair, alteration, accident, or for negligence in use, storage, transportation or handling or other negligence of Buyer. In no event shall Seller be liable for any Goods repaired or altered by someone other than Seller and Seller shall not be liable or responsible for the performance of computer equipment associated with the Goods that were not directly supplied by the Seller other than pursuant to written authorization by Seller.

11.7     Exclusive Obligation. This warranty is exclusive. The limited warranty and the limited warranty for services are the sole and exclusive obligations of seller with respect to the defective goods and services. Seller shall not have any other obligation with respect to the goods, services, or any part thereof, whether based on contract, tort, strict liability, or otherwise. The remedies set forth in sections 11.1 and 11.2 shall be the buyer’s sole and exclusive remedy and seller’s entire liability for any breach of the limited warranty set forth in section 11.1 and 11.2.

11.8     Buyer Breach. In no event shall Buyer be entitled to claim under the above Limited Warranties if Buyer is in breach of its obligations, including but not limited to payment, hereunder.

12. Limitation of Liability

12.1     In no event shall seller be liable for any consequential, indirect, incidental, special, exemplary, or punitive damages, lost profits or revenues or diminution in value, including without limitation, remanufacturing costs and rework costs, de-installation or re-installation cost, whether or not the possibility of such damages has been disclosed in advance by buyer or could have been reasonably foreseen by buyer, regardless of the legal or equitable theory (tort, contract, or otherwise) upon which the claim is based, and whatever the forum, whether arising out of or in connection with the manufacture, packaging, delivery, storage, use, misuse or non-use of any of its goods or services or any other cause whatsoever.

12.2     In no event shall seller’s aggregate liability arising out of or related to this agreement, whether arising out of or related to breach of contract, tort (including negligence) or otherwise, exceed the total of the amounts paid to seller for the goods sold hereunder.

12.3     The limitation of liability set forth in Section 12.2 above shall not apply to (i) liability resulting from Seller’s gross negligence or willful misconduct and (ii) death or bodily injury resulting from Seller’s acts or omissions.

13. Cancellation:

Buyer may not cancel this Agreement after Sales Confirmation is sent to Buyer unless all the details are approved in writing by the parties, including Buyer’s agreement to pay a stated amount of termination charges.

14. Termination:

In addition to any remedies that may be provided under these Terms, Seller may terminate this Agreement with immediate effect upon written notice to Buyer, if Buyer: (i) fails to pay any amount when due under this Agreement and such failure continues for 10 days after Buyer’s receipt of written notice of nonpayment; (ii) has not otherwise performed or complied with any of these Terms, in whole or in part; or (iii) becomes insolvent, files a petition for bankruptcy or commences or has commenced against it proceedings relating to bankruptcy, receivership, reorganization or assignment for the benefit of creditors.

15. Changes:

Seller shall not be obligated to implement any changes or variations in the scope of work described in Seller’s Documentation unless Buyer and Seller agree in writing to the details of the change and any resulting price, schedule or other contractual modifications. This includes any changes or variations necessitated by a change in applicable law occurring after the effective date of this Agreement including these Terms.

16. Intellectual Property Infringement:

Buyer has no authorization to make any representation, statement or warranty on behalf of Seller relating to any Goods sold hereunder. Buyer shall indemnify and defend, at its own expense, Seller against claims or liability for U.S. or applicable foreign patent, copyright, trademark or other intellectual property infringement and for product liability arising from the preparation or manufacture of the Goods according to Buyer’s specifications or instructions, or from Buyer’s unauthorized or improper use of the Goods or part thereof, or from any changes or alterations to the Goods or part thereof made by persons other than Seller, or from the use of the Goods in combination with products not furnished by Seller or from the manufacture or sale or use of Buyer products which incorporate or integrate the Goods.

17. Ownership of Materials:

All ideas, concepts, whether patentable or not, devices, inventions, copyrights, improvements or discoveries, designs (including drawings, plans and specifications), estimates, prices, notes, electronic data and other documents or information that are: a) created, prepared, reduced to practice or disclosed by Seller; and/or b) based upon, derived from, or utilize the Confidential Information of Seller, and all related intellectual property rights, shall at all times remain Seller’s property. No right, title or interest in any patents, trademarks, trade names or trade secrets, or in any pattern, drawing or design for any of the Goods or in any other Seller intellectual property right, shall pass or transfer to the Buyer and Seller shall at all times retain ownership rights therein. Notwithstanding the foregoing, Seller grants Buyer a non-exclusive, non-transferable license to use any such material to the extent necessary and solely for Buyer’s use of the Goods purchased by Buyer from Seller hereunder. Buyer shall not disclose any such material to third parties without Seller’s prior written consent. As a condition to Seller’s delivery to Buyer of the Goods, Buyer shall not, directly or indirectly, and shall cause its employees, agents and representatives not to: (i) alter or modify the Goods, (ii) disassemble, decompile or otherwise reverse engineer or analyze the Goods, (iii) remove any product identification or proprietary rights notices, (iv) modify or create derivative works, (v) otherwise take any action contrary to Seller’s rights in the technology and intellectual property relating to the Goods, (vi) assist or ask others to do any of the foregoing.

18. Export:

As a condition to Seller’s delivery to Buyer of the Goods, Buyer agrees, with respect to the exportation or resale of the Goods by Buyer, to comply with all requirements of the International Traffic in Arms Regulations ](“ITAR”) and the Export Administration Regulations (“EAR”), regulations issued thereunder and any subsequent amendments thereto, and all other national, including, but not limited to, European, government laws and regulations on export controls, including laws and regulations pertaining to export licenses, restrictions on export to embargoed countries and restrictions on sales to certain persons and/or entities. Buyer further agrees that the shipment and/or delivery of the Goods by Seller is contingent upon Seller obtaining all required export authorizations, licenses, and permits (collectively, “Authorizations”) and Buyer agrees that Seller shall not be liable to Buyer for any failure or delay in the shipment or delivery of the Goods if such Authorizations are delayed, conditioned, denied or not issued by the regulatory or governmental agencies having jurisdiction over such Authorizations.

19. Confidentiality:

If Seller discloses or grants Buyer access to any research, development, technical, economic, or other business information or “know-how” of a confidential nature, whether reduced to writing or not, Buyer will not use or disclose any such information to any other person or company at any time, without Seller’s prior written consent. In the event that Buyer and Seller have entered into a separate confidentiality agreement (the “Confidentiality Agreement”), the terms and conditions of the Confidentiality Agreement shall take precedence over the terms of this paragraph.

20. Right of First Offer:

In the event that Buyer chooses to dispose of the Goods through a third party private sale (auction or sale to a used instrument vendor or liquidator), Seller, at Seller’s own discretion has the right to match any Valid Offer made to Buyer by any third party and purchase back the Goods within 30 days of the Valid Offer being made known in writing to the Seller. A Valid Offer is defined as an offer in writing from a third party source deemed legitimate to the Seller. Seller has no obligations under these Terms to match any offer, nor does Seller have any obligation purchase back any Goods.

21. No Waiver:

No waiver by Seller of any of the provisions of this Agreement is effective unless explicitly set forth in writing and signed by Seller. Seller’s failure to exercise, or to delay in exercising, any right, remedy, power or privilege arising from this Agreement, or to insist on Buyer’s strict performance of these Terms shall not operate as or be construed as a waiver by Seller.

22. Force Majeure:

Whenever performance by Seller of any of its obligations hereunder, is substantially prevented by reason of any act of God, strike, lock out, or other industrial or transportation disturbance, fire, lack of materials, law, regulation or ordinance, war or war conditions, or by reason of any other matter beyond its reasonable control, then such performance shall be excused, and deemed suspended during the continuation of such event and for a reasonable time thereafter, delayed, or adjusted accordingly.

23. No Third-Party Beneficiaries:

This Agreement is for the sole benefit of the parties hereto and their respective successors and permitted assigns and nothing herein, express or implied, is intended to or shall confer upon any other person or entity any legal or equitable right, benefit or remedy of any nature whatsoever under or by reason of these Terms.

24. Relationship of the Parties:

The relationship between the parties is that of independent contractors. Nothing contained in this Agreement shall be construed as creating any agency, partnership, joint venture or other form of joint enterprise, employment or fiduciary relationship between the parties, and neither party shall have authority to contract for or bind the other party in any manner whatsoever.

25. Validity:

If any provision of this Agreement, the Sales Confirmation or these Terms is held by any competent authority to be invalid or unenforceable in whole or in any part, such provision shall be ineffective, but only to the extent of such invalidity or unenforceability, without invalidating the remainder of such provision nor the other provisions, which shall not be affected.

26. Governing Law:

This Agreement, and all the rights and duties of the parties arising from or relating in any way to the subject matter of this Agreement or the transaction(s) contemplated by it, shall be governed by the laws of the State of California USA, without giving effect to any choice or conflict of law provision or rule that would cause the application of the laws of any jurisdiction other than those of the State of California.

The parties expressly exclude the application of the United Nations Conventions on Contracts for the International Sale of Goods, and further exclude the applications of the International Sale of Goods Contracts Convention Act, S.C. 1990-1991, C.13, and the International Sale of Goods Act, R.S.O. 1990, C.I. 10, as amended.

27. Submission to Jurisdiction:

Buyer and Seller hereby unconditionally and irrevocably submit to (and waive any objection on the grounds of inconvenient forum or otherwise) the jurisdiction of the Supreme Court of the State of California, or the United States District Court for the Northern District of California, which courts shall have exclusive jurisdiction to adjudicate and determine any suit, action or proceeding regarding or relating to this Agreement and the purchase and supply of the Goods. A judgment, order or decision of those courts in respect of any such claim or dispute shall be conclusive and may be recognized and enforced by any courts of any state, country or other jurisdiction.

28. No Jury Trial:

Buyer and seller hereby irrevocably waive all right to trial by jury in any action, proceeding or counterclaim arising out of or relating to this agreement.

29. Survival:

All payment, confidentiality and indemnity obligations, warranties, limitations of liability, product return, and ownership of materials provisions together with those sections the survival of which is necessary for the interpretation or enforcement of these Terms, shall continue in full force and effect for the duration stated in such provisions or the applicable statute of limitations.

30. Amendment and Modification:

This Agreement may only be amended or modified in a writing which specifically states that it amends this Agreement and is signed by an authorized representative of each party.

PDF

Updated: February 13, 2023